Skip to Content

STANDARD TERMS AND CONDITIONS OF SALE

Below terms apply for any transaction involving WhyteWalls Design Studio's services:

General

  • These Terms & Conditions govern the use of our website and services offered by WhyteWalls Design Studio, a brand of AlbaMur Designs (OPC) Private Limited.
  • By engaging our services or accessing our website, you agree to comply with these terms.
  • Specific projects are governed by specific service agreement or works contract signed with individual clients.

Services

  • WhyteWalls Design Studio provides interior design and construction solutions as described in project-specific agreements.
  • All visuals, specifications, and descriptions on the website are indicative and subject to confirmation in the formal contract.

Pricing & Payments

  • Quotations shared are valid for a limited period (typically 30 days) unless otherwise stated.
  • Final pricing, payment milestones, and scope of work are subject to be detailed in the project-specific agreements
  • Prices may vary based on material availability, customization, or statutory changes.
  • Payments must be made as per agreed milestones in the project-specific agreements.
  • Delayed payments may attract interest charges and can affect project timelines.
  • Advance payments are non-refundable unless otherwise agreed in writing.

Quality & Warranty

  • WhyteWalls Design Studio adheres to Indian Standards and industry best practices.
  • Standard defects liability period of 6 months for Interior projects, and 12 months for Construction projects apply post-handover, covering workmanship and material defects unless stated otherwise in project-specific agreements.

Intellectual Property

  • All designs, drawings, and content shared by WhyteWalls Design Studio remain our intellectual property.
  • Customers may not reproduce, distribute, or share proprietary designs wit​hout prior written consent.

Limitation of Liability

  • WhyteWalls Design Studio will not be liable for indirect, incidental, or consequential damages arising from project delays, third-party actions, or force majeure events.

Dispute Resolution

  • Disputes shall first be resolved amicably.
  • Failing settlement, disputes will be referred to arbitration under the Arbitration and Conciliation Act, 1996, with Bengaluru as the seat of arbitration.

Governing Law

  • These Terms & Conditions are governed by the laws of India.